GJN50477 Pivot (WBGS) Contract - Laserfiche WebLink

New Search

, of the budget allocated for the Cost of the Work or contingencies included in the overall budget or a portion of the budget (i) mawrequire corresponding changes in the Project scope and quality (ii) may require. a chans;e in the schedule for the performance of the Architect's services and (iii) may result in a Change in Services. If changes in Project scope and quality are required the Owner shall cooperate with the Architect in revisin>; the Proiect scope and qualitx The schedule for the performance of the Architect's services shall be adjusted as necessary to reflect the time required on account of the foregoine changes If such changes result in a Change in Services, then the provisions of Paragraph 1.3.3 shall apply. § 1.2.2.3 The Owner's Designated Representative identified in Section 1.1.3.1-1-1:-3 shall be authorized to act on the Owner's behalf with respect to the Project. The Owner or the Owner's Designated Representative shall render decisions in a timely manner pertaining to documents submitted by the Architect in order to avoid unreasonable delay in the orderly and sequential progress of the Architect's ser-v~iees:services. and in accordance with the schedule approved bathe Owner. § 1.2.2.4 The Owner shall furnish the services of consultants other than those designated in Section 1.1.3 or authorize the Architect to famish them as a Change in Services when such services are requested by the Architect and are reasonably required by the scope of the Project. The Owner shall instruct all consultants retained either directly by the Owner or indirectly by the Owner throw hg other parties retained by the Owner to coordinate their services and work with that. of the Architect. i § 1.2.2.5 Unless otherwise provided in this Agreement, the Owner shall. furnish tests, inspections and reports required , by law or the Contract Documents, such as structural, mechanical, and chemical tests, tests for air and water pollution, and tests for hazardous materials. § 1.2.2.6 Except for insurance required to be provided by the Architect and anv Contractors. Subcontractors, and .Consultants, the Owner shall furnish all legal, insurance and accounting services, including auditing services, that may be reasonably necessary at any time for the Project to meet the Owner's needs and interests and such legal interpretations as the Architect may reasonably request with respect to applicable laws construction contract issues. and ~~~e~similar subjects relating to the Project which involve legal questions outside the normal expertise of Architects. § 1;2.2.7 The Owner shall provide prompt written notice to the Architect if the Owner becomes aware of any fault or defect in the Project, including any errors, omissions or inconsistencies in the Architect's Instruments of Service. § 1.2.3 ARCHITECT § 1.2.3.1 The services performed by the Architect, Architect's employees and Architect's consultants shall be as enumerated in Article 1.4. § 1.2.3.2 The Architect's services. shall be performed in accordance with applicable standards of professional practice and as expeditiously as is consistent with professional skill and care and the orderly progress of the Project. The Architect shall submit for the Owner's approval a schedule for the performance of the Architect's services which initially shall be consistent with the time periods established in Section 1.1.2.6 and which shall be adjusted, if necessary, as the Project proceeds. This schedule shall include allowances for periods of time required for the Owner's review, for the performance of the Owner's consultants, and for approval of submissions by authorities having jurisdiction over the Project. Time limits established by this schedule approved by the Owner shall not, except for reasonable cause, be exceeded by the Architect or Owner. § 1.2.3.3 The Architect's llCSignated Representative identiticJ iu Scetiun 1.1.3.4 shall be authorized to act on i the Architect's behalf with respect to the Project. § 1.2.3.4 The Architect shall maintain the confidentiality of information specifically designated as confidential by the Owner, unless withholding such information would violate the law, create the risk of significant harm to the public or prevent the Architect from establishing a claim or defense in an adjudicatory proceeding. The Architect shall require of the Architect's consultants similar written agreements to maintain the confidentiality of information specifically designated as confidential by the Owner. AIA Document B141TM -1997 Part 1. Copyright ©1917, 1926, 1948, 1951, 1953, 1958, 1961, 1963, 1966, 1967, 1970, 1974, 1977, 1987 and 1997 by The American Institute of Architects. All rights reserved. WARNING: This AIA' Document is protected by U.S. Copyright Law and International Treaties. 5 t)nauthorized reproduction or distribution of this AIA° Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 11:10:48 on 0 510 6/2 0 0 5 under Order No.1000157350_t which expires on 10/5/2005, and is not for resale. User Notes: (2107969202)