New Search
<br />Remedies. <br />6. <br /> <br />6.1 In the event of a termination of the Contract by City because of a breach by <br />Contractor, City may complete the Services either by itself or by contract with other <br />persons, or any combination thereof. Contractor shall be liable to City for any costs <br />or losses incurred by City arising out of or related to the breach, including costs <br />incurred in selecting other contractors, time-delay losses, attorney fees and the like, <br />less the remaining unpaid balance of the consideration provided in the Contract. City <br />may withhold payment of sums due Contractor for Services performed to the date of <br />termination until City’s costs and losses have been determined, at which time City <br />may offset any such amount due Contractor against the costs and losses incurred by <br />City. <br /> <br />6.2 The foregoing remedies provided to City for breach of the Contract by Contractor <br />shall not be exclusive. City shall be entitled to exercise any one or more other legal <br />or equitable remedies available because of Contractor’s breach with or without <br />termination. <br /> <br />6.3 In the event of breach of the Contract by City, Contractor’s remedy shall be limited to <br />termination of the Contract and payment for Services performed to the date of <br />termination less any offset to which City is entitled. <br /> <br />Records/Inspection. <br />7. Contractor shall maintain records of its charges to City under the <br />Contract for a period of not less than three years following Contractor’s completion of the <br />Contract. Upon reasonable advance notice, City or its authorized representatives may from <br />time to time inspect, audit and make copies of any Contractor’s records that relate to the <br />Contract. If any audit by City discloses that payments to the Contractor were in excess of <br />the amount to which Contractor was entitled under the Contract, Contractor shall promptly <br />pay to City the amount of such excess. If the excess charged by Contractor for any audited <br />period is greater than two percent of the amount that should have been charged for that <br />period, Contractor shall also reimburse City its reasonable costs incurred in performing the <br />audit. <br /> <br />Indemnification. <br />8. Contractor shall indemnify and hold City, and its officers, agents and <br />employees, harmless from and against all claims, actions, liabilities, costs, including attorney <br />fees and other costs of defense, arising out of or in any way related to the acts, errors or <br />omissions, whether alleged or actual, of Contractor, its subcontractors, agents and <br />employees in performing or failing to perform the Services, failing to strictly comply with any <br />provision of the Contract or any other actions or failures to act by Contractor and <br />Contractor’s employees, agents, and subcontractors. In the event any such action or claim <br />is brought against City, Contractor shall, if City so elects and upon tender by City, defend <br />the same at Contractor’s sole cost and expense, promptly satisfy any judgment adverse to <br />City or to City and Contractor, jointly, and reimburse City for any loss, cost, damage or <br />expense, including attorney fees, suffered or incurred by City. City shall notify Contractor, <br />within a reasonable time, of any claim, threat of claim or legal action subject to the <br />provisions of this Section 8. <br /> <br />Insurance. <br />9. Contractor shall have and maintain the insurance policies specified below. <br />Each policy of insurance shall be written as a primary policy, not contributing with or in <br />excess of any coverage which City may carry. A copy of each policy or a certificate <br /> <br /> <br />