New Search
<br />delay, the parties have estimated the amount City would be damaged for every working day <br />completion is delayed. The parties believe that the sum set as liquidated damages is reasonably <br />related to City's anticipated damages per working day after the Completion Date that the Work is <br />not completed. Contractor will not contest such sum as being other than a true measure of damages <br />in the event those damages become payable under these provisions. <br />26. Arbitration. All claims or disputes between City and Contractor arising out of or related to the <br />Work or this contract shall be decided by arbitration conducted in accordance with the construction <br />industry arbitration rules of the American Arbitration Association unless the parties agree <br />otherwise. The parties shall bear equally the administrative fees of the American Arbitration <br />Association and the fees of the arbitrator. <br />27. Notices. Any notices permitted or required by this contract shall be deemed given when personally <br />delivered or upon deposit in the United States mail, postage fully prepaid, certified, return receipt <br />requested, addressed to: <br />Contractor: Richard Kimbell, Sales Manager <br />Lile-Eugene Moving & Storage <br />330 Roosevelt Blvd. <br />Eugene, OR 97402 <br />City: Russ Mecredy, Project Manager <br />City of Eugene Facility Management Division <br />210 Cheshire Avenue <br />Eugene, OR 97401 <br />or such other address as either party may provide to the other by notice given in accordance with <br />this provision. <br />28. Contract Documents/Interpretation. This contract, together with the other documents <br />enumerated below, which are hereby incorporated by reference, forms the entire contract between <br />the parties hereto. In the event that any provision of any component part of this contract conflicts <br />with any provisions of any other component part, the provisions of the component part first <br />enumerated below shall govern, except as otherwise specifically agreed: <br />28.1 Permits from government agencies. <br />28.2 The public improvement contract. <br />28.3 Addenda to the Special Specifications. <br />28.4 Special Specifications. <br />28.5 Plans specifically applicable to the project. <br />28.6 Supplemental Standard Specifications. <br />Public Improvement Contract (Comp)--Page 10 <br />(Revised April 1998) <br />